Privacy Policy

Privacy Policy

By using the website in any manner, including but not limited to visiting or browsing the Site, you (the "User" or "You") agree to be bound by the terms of this Agreement:

APPLICABLE:

The Terms and Condition apply to Users of the website with immediate effect. The Website may revise these Terms and Conditions at any time without any notice by updating this post. User will be bound by any such updates of these terms and conditions.

Website Regulations

Users agree that they will use the website for lawful purpose and in lawful manner. While using the website, you abide to the following rules:

Services:

These are services provided based on Projects that have a Statement of Work and Timeline with a Project initiation date and completion date. Custom Projects includes:
1. Mobile App Development
2. Mobile Product Strategy
3. Strategic Design Consultancy
4. Mobile App QA and Testing
5. Web Portal and Development
6. Connected Devices

Payments:

The Digital Elliptical accepts payments using credit cards, wire transfer and check only. Online payments using credit cards and debit cards will only be made where the total project cost is less than $4000. In case the project cost is more than $5000, the total cost will be broken into parts based on project timelines and milestones and will be done through wire or check. All orders will be executed based on the signed contract between the company and the customer. Customer is bind to agree the contract terms for Payment schedule.

Refunds:

Refunds will be applicable only for milestones that have not been delivered to the client as per the contract. After the Contract is signed, Client accepts and understands the project deliverables on a specified time. All approved project deliverables will NOT be included in the refund process including any delays in the deliverables where the delay was caused due to nonavailability of client for feedback and issues with 3rd party API/Plug-ins used for integration.

Resolution Of Disputes:

If a dispute arises, The Digital Elliptical goal is to resolve such dispute amicably. Accordingly, you and we agree that we will resolve any claim or dispute that arises between you and the company of this Agreement or the Services (a “Claim”) in accordance with this section, entitled “Resolution of Disputes.” Before resorting to any other alternatives, you agree to first contact us directly to seek a resolution.

You agree that by entering into this agreement, you and The Digital Elliptical are each waiving the right to trial by jury or to participate in a class action. You and The Digital Elliptical agree that each may bring claims against the other only in your or its individual capacity and not as a plaintiff or class member in any purported class or representative proceeding. Any arbitration will take place on an individual basis; class arbitrations and class actions are not permitted.